tsm
International Program License Agreement
Part 1 - General Terms
BY DOWNLOADING, INSTALLING, COPYING, ACCESSING, CLICKING ON AN "ACCEPT" BUTTON, OR OTHERWISE USING
THE PROGRAM, LICENSEE AGREES TO THE TERMS OF THIS AGREEMENT. IF YOU ARE ACCEPTING THESE TERMS ON
BEHALF OF LICENSEE, YOU REPRESENT AND WARRANT THAT YOU HAVE FULL AUTHORITY TO BIND LICENSEE TO
THESE TERMS. IF YOU DO NOT AGREE TO THESE TERMS,
- DO NOT DOWNLOAD, INSTALL, COPY, ACCESS, CLICK ON AN "ACCEPT" BUTTON, OR USE THE PROGRAM; AND
- PROMPTLY RETURN THE UNUSED MEDIA, DOCUMENTATION, AND PROOF OF ENTITLEMENT TO THE PARTY FROM WHOM
IT WAS OBTAINED FOR A REFUND OF THE AMOUNT PAID. IF THE PROGRAM WAS DOWNLOADED, DESTROY ALL COPIES
OF THE PROGRAM.
1. Definitions
"Authorized Use" - the specified level at which Licensee is authorized to execute or run the
Program. That level may be measured by number of users, millions of service units ("MSUs"),
Processor Value Units ("PVUs"), or other level of use specified by IBM.
"IBM" - International Business Machines Corporation or one of its subsidiaries.
"License Information" ("LI") - a document that provides information and any additional terms
specific to a Program. The Program's LI is available at www.ibm.com/software/sla. The LI can also
be found in the Program's directory, by the use of a system command, or as a booklet included with
the Program.
"Program" - the following, including the original and all whole or partial copies: 1)
machine-readable instructions and data, 2) components, files, and modules, 3) audio-visual content
(such as images, text, recordings, or pictures), and 4) related licensed materials (such as keys
and documentation).
"Proof of Entitlement" ("PoE") - evidence of Licensee's Authorized Use. The PoE is also evidence of
Licensee's eligibility for warranty, future update prices, if any, and potential special or
promotional opportunities. If IBM does not provide Licensee with a PoE, then IBM may accept as the
PoE the original paid sales receipt or other sales record from the party (either IBM or its
reseller) from whom Licensee obtained the Program, provided that it specifies the Program name and
Authorized Use obtained.
"Warranty Period" - one year, starting on the date the original Licensee is granted the license.
2. Agreement Structure
This Agreement includes Part 1 - General Terms, Part 2 - Country-unique Terms (if any), the LI, and
the PoE and is the complete agreement between Licensee and IBM regarding the use of the Program. It
replaces any prior oral or written communications between Licensee and IBM concerning Licensee's
use of the Program. The terms of Part 2 may replace or modify those of Part 1. To the extent of any
conflict, the LI prevails over both Parts.
3. License Grant
The Program is owned by IBM or an IBM supplier, and is copyrighted and licensed, not sold.
IBM grants Licensee a nonexclusive license to 1) use the Program up to the Authorized Use specified
in the PoE, 2) make and install copies to support such Authorized Use, and 3) make a backup copy,
all provided that
a. Licensee has lawfully obtained the Program and complies with the terms of this Agreement;
b. the backup copy does not execute unless the backed-up Program cannot execute;
c. Licensee reproduces all copyright notices and other legends of ownership on each copy, or
partial copy, of the Program;
d. Licensee ensures that anyone who uses the Program (accessed either locally or remotely) 1) does
so only on Licensee's behalf and 2) complies with the terms of this Agreement;
e. Licensee does not 1) use, copy, modify, or distribute the Program except as expressly permitted
in this Agreement; 2) reverse assemble, reverse compile, otherwise translate, or reverse engineer
the Program, except as expressly permitted by law without the possibility of contractual waiver; 3)
use any of the Program's components, files, modules, audio-visual content, or related licensed
materials separately from that Program; or 4) sublicense, rent, or lease the Program; and
f. if Licensee obtains this Program as a Supporting Program, Licensee uses this Program only to
support the Principal Program and subject to any limitations in the license to the Principal
Program, or, if Licensee obtains this Program as a Principal Program, Licensee uses all Supporting
Programs only to support this Program, and subject to any limitations in this Agreement. For
purposes of this Item "f," a "Supporting Program" is a Program that is part of another IBM Program
("Principal Program") and identified as a Supporting Program in the Principal Program's LI. (To
obtain a separate license to a Supporting Program without these restrictions, Licensee should
contact the party from whom Licensee obtained the Supporting Program.)
This license applies to each copy of the Program that Licensee makes.
3.1 Trade-ups, Updates, Fixes, and Patches
3.1.1 Trade-ups
If the Program is replaced by a trade-up Program, the replaced Program's license is promptly
terminated.
3.1.2 Updates, Fixes, and Patches
When Licensee receives an update, fix, or patch to a Program, Licensee accepts any additional or
different terms that are applicable to such update, fix, or patch that are specified in its LI. If
no additional or different terms are provided, then the update, fix, or patch is subject solely to
this Agreement. If the Program is replaced by an update, Licensee agrees to promptly discontinue
use of the replaced Program.
3.2 Fixed Term Licenses
If IBM licenses the Program for a fixed term, Licensee's license is terminated at the end of the
fixed term, unless Licensee and IBM agree to renew it.
3.3 Term and Termination
This Agreement is effective until terminated.
IBM may terminate Licensee's license if Licensee fails to comply with the terms of this Agreement.
If the license is terminated for any reason by either party, Licensee agrees to promptly
discontinue use of and destroy all of Licensee's copies of the Program. Any terms of this Agreement
that by their nature extend beyond termination of this Agreement remain in effect until fulfilled,
and apply to both parties' respective successors and assignees.
4. Charges
Charges are based on Authorized Use obtained, which is specified in the PoE. IBM does not give
credits or refunds for charges already due or paid, except as specified elsewhere in this
Agreement.
If Licensee wishes to increase its Authorized Use, Licensee must notify IBM or an authorized IBM
reseller in advance and pay any applicable charges.
5. Taxes
If any authority imposes on the Program a duty, tax, levy, or fee, excluding those based on IBM's
net income, then Licensee agrees to pay that amount, as specified in an invoice, or supply
exemption documentation. Licensee is responsible for any personal property taxes for the Program
from the date that Licensee obtains it. If any authority imposes a customs duty, tax, levy, or fee
for the import into or the export, transfer, access, or use of the Program outside the country in
which the original Licensee was granted the license, then Licensee agrees that it is responsible
for, and will pay, any amount imposed.
6. Money-back Guarantee
If Licensee is dissatisfied with the Program for any reason and is the original Licensee, Licensee
may terminate the license and obtain a refund of the amount Licensee paid for the Program, provided
that Licensee returns the Program and PoE to the party from whom Licensee obtained it within 30
days of the date the PoE was issued to Licensee. If the license is for a fixed term that is subject
to renewal, then Licensee may obtain a refund only if the Program and its PoE are returned within
the first 30 days of the initial term. If Licensee downloaded the Program, Licensee should contact
the party from whom Licensee obtained it for instructions on how to obtain the refund.
7. Program Transfer
Licensee may transfer the Program and all of Licensee's license rights and obligations to another
party only if that party agrees to the terms of this Agreement. If the license is terminated for
any reason by either party, Licensee is prohibited from transferring the Program to another party.
Licensee may not transfer a portion of 1) the Program or 2) the Program's Authorized Use. When
Licensee transfers the Program, Licensee must also transfer a hard copy of this Agreement,
including the LI and PoE. Immediately after the transfer, Licensee's license terminates.
8. Warranty and Exclusions
8.1 Limited Warranty
IBM warrants that the Program, when used in its specified operating environment, will conform to
its specifications. The Program's specifications, and specified operating environment information,
can be found in documentation accompanying the Program (such as a read-me file) or other
information published by IBM (such as an announcement letter). Licensee agrees that such
documentation and other Program content may be supplied only in the English language, unless
otherwise required by local law without the possibility of contractual waiver or limitation.
The warranty applies only to the unmodified portion of the Program. IBM does not warrant
uninterrupted or error-free operation of the Program, or that IBM will correct all Program defects.
Licensee is responsible for the results obtained from the use of the Program.
During the Warranty Period, IBM provides Licensee with access to IBM databases containing
information on known Program defects, defect corrections, restrictions, and bypasses at no
additional charge. Consult the IBM Software Support Handbook for further information at
www.ibm.com/software/support.
If the Program does not function as warranted during the Warranty Period and the problem cannot be
resolved with information available in the IBM databases, Licensee may return the Program and its
PoE to the party (either IBM or its reseller) from whom Licensee obtained it and receive a refund
of the amount Licensee paid. After returning the Program, Licensee's license terminates. If
Licensee downloaded the Program, Licensee should contact the party from whom Licensee obtained it
for instructions on how to obtain the refund.
8.2 Exclusions
THESE WARRANTIES ARE LICENSEE'S EXCLUSIVE WARRANTIES AND REPLACE ALL OTHER WARRANTIES OR
CONDITIONS, EXPRESS OR IMPLIED, INCLUDING, BUT NOT LIMITED TO, ANY IMPLIED WARRANTIES OR CONDITIONS
OF MERCHANTABILITY, SATISFACTORY QUALITY, FITNESS FOR A PARTICULAR PURPOSE, TITLE, AND ANY WARRANTY
OR CONDITION OF NON-INFRINGEMENT. SOME STATES OR JURISDICTIONS DO NOT ALLOW THE EXCLUSION OF
EXPRESS OR IMPLIED WARRANTIES, SO THE ABOVE EXCLUSION MAY NOT APPLY TO LICENSEE. IN THAT EVENT,
SUCH WARRANTIES ARE LIMITED IN DURATION TO THE WARRANTY PERIOD. NO WARRANTIES APPLY AFTER THAT
PERIOD. SOME STATES OR JURISDICTIONS DO NOT ALLOW LIMITATIONS ON HOW LONG AN IMPLIED WARRANTY
LASTS, SO THE ABOVE LIMITATION MAY NOT APPLY TO LICENSEE.
THESE WARRANTIES GIVE LICENSEE SPECIFIC LEGAL RIGHTS. LICENSEE MAY ALSO HAVE OTHER RIGHTS THAT VARY
FROM STATE TO STATE OR JURISDICTION TO JURISDICTION.
THE WARRANTIES IN THIS SECTION 8 (WARRANTY AND EXCLUSIONS) ARE PROVIDED SOLELY BY IBM. THE
DISCLAIMERS IN THIS SUBSECTION 8.2 (EXCLUSIONS), HOWEVER, ALSO APPLY TO IBM'S SUPPLIERS OF THIRD
PARTY CODE. THOSE SUPPLIERS PROVIDE SUCH CODE WITHOUT WARRANTIES OR CONDITION OF ANY KIND. THIS
PARAGRAPH DOES NOT NULLIFY IBM'S WARRANTY OBLIGATIONS UNDER THIS AGREEMENT.
9. Licensee Data and Databases
To assist Licensee in isolating the cause of a problem with the Program, IBM may request that
Licensee 1) allow IBM to remotely access Licensee's system or 2) send Licensee information or
system data to IBM. However, IBM is not obligated to provide such assistance unless IBM and
Licensee enter a separate written agreement under which IBM agrees to provide to Licensee that type
of technical support, which is beyond IBM's warranty obligations in this Agreement. In any event,
IBM uses information about errors and problems to improve its products and services, and assist
with its provision of related support offerings. For these purposes, IBM may use IBM entities and
subcontractors (including in one or more countries other than the one in which Licensee is
located), and Licensee authorizes IBM to do so.
Licensee remains responsible for 1) any data and the content of any database Licensee makes
available to IBM, 2) the selection and implementation of procedures and controls regarding access,
security, encryption, use, and transmission of data (including any personally-identifiable data),
and 3) backup and recovery of any database and any stored data. Licensee will not send or provide
IBM access to any personally-identifiable information, whether in data or any other form, and will
be responsible for reasonable costs and other amounts that IBM may incur relating to any such
information mistakenly provided to IBM or the loss or disclosure of such information by IBM,
including those arising out of any third party claims.
10. Limitation of Liability
The limitations and exclusions in this Section 10 (Limitation of Liability) apply to the full
extent they are not prohibited by applicable law without the possibility of contractual waiver.
10.1 Items for Which IBM May Be Liable
Circumstances may arise where, because of a default on IBM's part or other liability, Licensee is
entitled to recover damages from IBM. Regardless of the basis on which Licensee is entitled to
claim damages from IBM (including fundamental breach, negligence, misrepresentation, or other
contract or tort claim), IBM's entire liability for all claims in the aggregate arising from or
related to each Program or otherwise arising under this Agreement will not exceed the amount of any
1) damages for bodily injury (including death) and damage to real property and tangible personal
property and 2) other actual direct damages up to the charges (if the Program is subject to fixed
term charges, up to twelve months' charges) Licensee paid for the Program that is the subject of
the claim.
This limit also applies to any of IBM's Program developers and suppliers. It is the maximum for
which IBM and its Program developers and suppliers are collectively responsible.
10.2 Items for Which IBM Is Not Liable
UNDER NO CIRCUMSTANCES IS IBM, ITS PROGRAM DEVELOPERS OR SUPPLIERS LIABLE FOR ANY OF THE FOLLOWING,
EVEN IF INFORMED OF THEIR POSSIBILITY:
a. LOSS OF, OR DAMAGE TO, DATA;
b. SPECIAL, INCIDENTAL, EXEMPLARY, OR INDIRECT DAMAGES, OR FOR ANY ECONOMIC CONSEQUENTIAL DAMAGES;
OR
c. LOST PROFITS, BUSINESS, REVENUE, GOODWILL, OR ANTICIPATED SAVINGS.
11. Compliance Verification
For purposes of this Section 11 (Compliance Verification), "IPLA Program Terms" means 1) this
Agreement and applicable amendments and transaction documents provided by IBM, and 2) IBM software
policies that may be found at the IBM Software Policy website (www.ibm.com/softwarepolicies),
including but not limited to those policies concerning backup, sub-capacity pricing, and migration.
The rights and obligations set forth in this Section 11 remain in effect during the period the
Program is licensed to Licensee, and for two years thereafter.
11.1 Verification Process
Licensee agrees to create, retain, and provide to IBM and its auditors accurate written records,
system tool outputs, and other system information sufficient to provide auditable verification that
Licensee's use of all Programs is in compliance with the IPLA Program Terms, including, without
limitation, all of IBM's applicable licensing and pricing qualification terms. Licensee is
responsible for 1) ensuring that it does not exceed its Authorized Use, and 2) remaining in
compliance with IPLA Program Terms.
Upon reasonable notice, IBM may verify Licensee's compliance with IPLA Program Terms at all sites
and for all environments in which Licensee uses (for any purpose) Programs subject to IPLA Program
Terms. Such verification will be conducted in a manner that minimizes disruption to Licensee's
business, and may be conducted on Licensee's premises, during normal business hours. IBM may use an
independent auditor to assist with such verification, provided IBM has a written confidentiality
agreement in place with such auditor.
11.2 Resolution
IBM will notify Licensee in writing if any such verification indicates that Licensee has used any
Program in excess of its Authorized Use or is otherwise not in compliance with the IPLA Program
Terms. Licensee agrees to promptly pay directly to IBM the charges that IBM specifies in an invoice
for 1) any such excess use, 2) support for such excess use for the lesser of the duration of such
excess use or two years, and 3) any additional charges and other liabilities determined as a result
of such verification.
12. Third Party Notices
The Program may include third party code that IBM, not the third party, licenses to Licensee under
this Agreement. Notices, if any, for the third party code ("Third Party Notices") are included for
Licensee's information only. These notices can be found in the Program's NOTICES file(s).
Information on how to obtain source code for certain third party code can be found in the Third
Party Notices. If in the Third Party Notices IBM identifies third party code as "Modifiable Third
Party Code," IBM authorizes Licensee to 1) modify the Modifiable Third Party Code and 2) reverse
engineer the Program modules that directly interface with the Modifiable Third Party Code provided
that it is only for the purpose of debugging Licensee's modifications to such third party code.
IBM's service and support obligations, if any, apply only to the unmodified Program.
13. General
a. Nothing in this Agreement affects any statutory rights of consumers that cannot be waived or
limited by contract.
b. For Programs IBM provides to Licensee in tangible form, IBM fulfills its shipping and delivery
obligations upon the delivery of such Programs to the IBM-designated carrier, unless otherwise
agreed to in writing by Licensee and IBM.
c. If any provision of this Agreement is held to be invalid or unenforceable, the remaining
provisions of this Agreement remain in full force and effect.
d. Licensee agrees to comply with all applicable export and import laws and regulations, including
U.S. embargo and sanctions regulations and prohibitions on export for certain end uses or to
certain users.
e. Licensee authorizes International Business Machines Corporation and its subsidiaries (and their
successors and assigns, contractors and IBM Business Partners) to store and use Licensee's business
contact information wherever they do business, in connection with IBM products and services, or in
furtherance of IBM's business relationship with Licensee.
f. Each party will allow the other reasonable opportunity to comply before it claims that the other
has not met its obligations under this Agreement. The parties will attempt in good faith to resolve
all disputes, disagreements, or claims between the parties relating to this Agreement.
g. Unless otherwise required by applicable law without the possibility of contractual waiver or
limitation: 1) neither party will bring a legal action, regardless of form, for any claim arising
out of or related to this Agreement more than two years after the cause of action arose; and 2)
upon the expiration of such time limit, any such claim and all respective rights related to the
claim lapse.
h. Neither Licensee nor IBM is responsible for failure to fulfill any obligations due to causes
beyond its control.
i. No right or cause of action for any third party is created by this Agreement, nor is IBM
responsible for any third party claims against Licensee, except as permitted in Subsection 10.1
(Items for Which IBM May Be Liable) above for bodily injury (including death) or damage to real or
tangible personal property for which IBM is legally liable to that third party.
j. In entering into this Agreement, neither party is relying on any representation not specified in
this Agreement, including but not limited to any representation concerning: 1) the performance or
function of the Program, other than as expressly warranted in Section 8 (Warranty and Exclusions)
above; 2) the experiences or recommendations of other parties; or 3) any results or savings that
Licensee may achieve.
k. IBM has signed agreements with certain organizations (called "IBM Business Partners") to
promote, market, and support certain Programs. IBM Business Partners remain independent and
separate from IBM. IBM is not responsible for the actions or statements of IBM Business Partners or
obligations they have to Licensee.
l. The license and intellectual property indemnification terms of Licensee's other agreements with
IBM (such as the IBM Customer Agreement) do not apply to Program licenses granted under this
Agreement.
14. Geographic Scope and Governing Law
14.1 Governing Law
Both parties agree to the application of the laws of the country in which Licensee obtained the
Program license to govern, interpret, and enforce all of Licensee's and IBM's respective rights,
duties, and obligations arising from, or relating in any manner to, the subject matter of this
Agreement, without regard to conflict of law principles.
The United Nations Convention on Contracts for the International Sale of Goods does not apply.
14.2 Jurisdiction
All rights, duties, and obligations are subject to the courts of the country in which Licensee
obtained the Program license.
Part 2 - Country-unique Terms
For licenses granted in the countries specified below, the following terms replace or modify the
referenced terms in Part 1. All terms in Part 1 that are not changed by these amendments remain
unchanged and in effect. This Part 2 is organized as follows:
- Multiple country amendments to Part 1, Section 14 (Governing Law and Jurisdiction);
- Americas country amendments to other Agreement terms;
- Asia Pacific country amendments to other Agreement terms; and
- Europe, Middle East, and Africa country amendments to other Agreement terms.
Multiple country amendments to Part 1, Section 14 (Governing Law and Jurisdiction)
14.1 Governing Law
The phrase "the laws of the country in which Licensee obtained the Program license" in the first
paragraph of 14.1 Governing Law is replaced by the following phrases in the countries below:
AMERICAS
(1) in Canada: the laws in the Province of Ontario;
(2) in Mexico: the federal laws of the Republic of Mexico;
(3) in the United States, Anguilla, Antigua/Barbuda, Aruba, British Virgin Islands, Cayman Islands,
Dominica, Grenada, Guyana, Saint Kitts and Nevis, Saint Lucia, Saint Maarten, and Saint Vincent and
the Grenadines: the laws of the State of New York, United States;
(4) in Venezuela: the laws of the Bolivarian Republic of Venezuela;
ASIA PACIFIC
(5) in Cambodia and Laos: the laws of the State of New York, United States;
(6) in Australia: the laws of the State or Territory in which the transaction is performed;
(7) in Hong Kong SAR and Macau SAR: the laws of Hong Kong Special Administrative Region ("SAR");
(8) in Taiwan: the laws of Taiwan
EUROPE, MIDDLE EAST, AND AFRICA
(9) in Albania, Armenia, Azerbaijan, Belarus, Bosnia-Herzegovina, Bulgaria, Croatia, Former
Yugoslav Republic of Macedonia, Georgia, Hungary, Kazakhstan, Kyrgyzstan, Moldova, Montenegro,
Poland, Romania, Russia, Serbia, Slovakia, Tajikistan, Turkmenistan, Ukraine, and Uzbekistan: the
laws of Austria;
(10) in Algeria, Andorra, Benin, Burkina Faso, Cameroon, Cape Verde, Central African Republic,
Chad, Comoros, Congo Republic, Djibouti, Democratic Republic of Congo, Equatorial Guinea, French
Guiana, French Polynesia, Gabon, Gambia, Guinea, Guinea-Bissau, Ivory Coast, Lebanon, Madagascar,
Mali, Mauritania, Mauritius, Mayotte, Morocco, New Caledonia, Niger, Reunion, Senegal, Seychelles,
Togo, Tunisia, Vanuatu, and Wallis and Futuna: the laws of France;
(11) in Estonia, Latvia, and Lithuania: the laws of Finland;
(12) in Angola, Bahrain, Botswana, Burundi, Egypt, Eritrea, Ethiopia, Ghana, Jordan, Kenya, Kuwait,
Liberia, Malawi, Malta, Mozambique, Nigeria, Oman, Pakistan, Qatar, Rwanda, Sao Tome and Principe,
Saudi Arabia, Sierra Leone, Somalia, Tanzania, Uganda, United Arab Emirates, the United Kingdom,
West Bank/Gaza, Yemen, Zambia, and Zimbabwe: the laws of England; and
(13) in South Africa, Namibia, Lesotho, and Swaziland: the laws of the Republic of South Africa.
14.2 Jurisdiction
The following paragraph pertains to jurisdiction and replaces Subsection 14.2 (Jurisdiction) as it
applies for those countries identified in bold below:
All rights, duties, and obligations are subject to the courts of the country in which Licensee
obtained the Program license except that in the countries identified below all disputes arising out
of or related to this Agreement, including summary proceedings, will be brought before and subject
to the exclusive jurisdiction of the following courts of competent jurisdiction:
AMERICAS
(1) in Argentina: the Ordinary Commercial Court of the city of Buenos Aires,
(2) in Brazil: the court of Rio de Janeiro, RJ;
(3) in Chile: the Civil Courts of Justice of Santiago;
(4) in Ecuador: the civil judges of Quito for executory or summary proceedings (as applicable);
(5) in Mexico: the courts located in Mexico City, Federal District;
(6) in Peru: the judges and tribunals of the judicial district of Lima, Cercado;
(7) in Uruguay: the courts of the city of Montevideo;
(8) in Venezuela: the courts of the metropolitan area of the city of Caracas;
EUROPE, MIDDLE EAST, AND AFRICA
(9) in Austria: the court of law in Vienna, Austria (Inner-City);
(10) in Algeria, Andorra, Benin, Burkina Faso, Cameroon, Cape Verde, Central African Republic,
Chad, Comoros, Congo Republic, Djibouti, Democratic Republic of Congo, Equatorial Guinea, France,
French Guiana, French Polynesia, Gabon, Gambia, Guinea, Guinea-Bissau, Ivory Coast, Lebanon,
Madagascar, Mali, Mauritania, Mauritius, Mayotte, Monaco, Morocco, New Caledonia, Niger, Reunion,
Senegal, Seychelles, Togo, Tunisia, Vanuatu, and Wallis and Futuna: the Commercial Court of Paris;
(11) in Angola, Bahrain, Botswana, Burundi, Egypt, Eritrea, Ethiopia, Ghana, Jordan, Kenya, Kuwait,
Liberia, Malawi, Malta, Mozambique, Nigeria, Oman, Pakistan, Qatar, Rwanda, Sao Tome and Principe,
Saudi Arabia, Sierra Leone, Somalia, Tanzania, Uganda, United Arab Emirates, the United Kingdom,
West Bank/Gaza, Yemen, Zambia, and Zimbabwe: the English courts;
(12) in South Africa, Namibia, Lesotho, and Swaziland: the High Court in Johannesburg;
(13) in Greece: the competent court of Athens;
(14) in Israel: the courts of Tel Aviv-Jaffa;
(15) in Italy: the courts of Milan;
(16) in Portugal: the courts of Lisbon;
(17) in Spain: the courts of Madrid; and
(18) in Turkey: the Istanbul Central Courts and Execution Directorates of Istanbul, the Republic of
Turkey.
14.3 Arbitration
The following paragraph is added as a new Subsection 14.3 (Arbitration) as it applies for those
countries identified in bold below. The provisions of this Subsection 14.3 prevail over those of
Subsection 14.2 (Jurisdiction) to the extent permitted by the applicable governing law and rules of
procedure:
ASIA PACIFIC
(1) In Cambodia, India, Indonesia, Laos, Philippines, and Vietnam:
Disputes arising out of or in connection with this Agreement will be finally settled by arbitration
which will be held in Singapore in accordance with the Arbitration Rules of Singapore International
Arbitration Center ("SIAC Rules") then in effect. The arbitration award will be final and binding
for the parties without appeal and will be in writing and set forth the findings of fact and the
conclusions of law.
The number of arbitrators will be three, with each side to the dispute being entitled to appoint
one arbitrator. The two arbitrators appointed by the parties will appoint a third arbitrator who
will act as chairman of the proceedings. Vacancies in the post of chairman will be filled by the
president of the SIAC. Other vacancies will be filled by the respective nominating party.
Proceedings will continue from the stage they were at when the vacancy occurred.
If one of the parties refuses or otherwise fails to appoint an arbitrator within 30 days of the
date the other party appoints its, the first appointed arbitrator will be the sole arbitrator,
provided that the arbitrator was validly and properly appointed. All proceedings will be conducted,
including all documents presented in such proceedings, in the English language. The English
language version of this Agreement prevails over any other language version.
(2) In the People's Republic of China:
In case no settlement can be reached, the disputes will be submitted to China International
Economic and Trade Arbitration Commission for arbitration according to the then effective rules of
the said Arbitration Commission. The arbitration will take place in Beijing and be conducted in
Chinese. The arbitration award will be final and binding on both parties. During the course of
arbitration, this agreement will continue to be performed except for the part which the parties are
disputing and which is undergoing arbitration.
EUROPE, MIDDLE EAST, AND AFRICA
(3) In Albania, Armenia, Azerbaijan, Belarus, Bosnia-Herzegovina, Bulgaria, Croatia, Former
Yugoslav Republic of Macedonia, Georgia, Hungary, Kazakhstan, Kyrgyzstan, Moldova, Montenegro,
Poland, Romania, Russia, Serbia, Slovakia, Tajikistan, Turkmenistan, Ukraine, and Uzbekistan:
All disputes arising out of this Agreement or related to its violation, termination or nullity will
be finally settled under the Rules of Arbitration and Conciliation of the International Arbitral
Center of the Federal Economic Chamber in Vienna (Vienna Rules) by three arbitrators appointed in
accordance with these rules. The arbitration will be held in Vienna, Austria, and the official
language of the proceedings will be English. The decision of the arbitrators will be final and
binding upon both parties. Therefore, pursuant to paragraph 598 (2) of the Austrian Code of Civil
Procedure, the parties expressly waive the application of paragraph 595 (1) figure 7 of the Code.
IBM may, however, institute proceedings in a competent court in the country of installation.
(4) In Estonia, Latvia, and Lithuania:
All disputes arising in connection with this Agreement will be finally settled in arbitration that
will be held in Helsinki, Finland in accordance with the arbitration laws of Finland then in
effect. Each party will appoint one arbitrator. The arbitrators will then jointly appoint the
chairman. If arbitrators cannot agree on the chairman, then the Central Chamber of Commerce in
Helsinki will appoint the chairman.
AMERICAS COUNTRY AMENDMENTS
CANADA
10.1 Items for Which IBM May be Liable
The following replaces Item 1 in the first paragraph of this Subsection 10.1 (Items for Which IBM
May be Liable):
1) damages for bodily injury (including death) and physical harm to real property and tangible
personal property caused by IBM's negligence; and
13. General
The following replaces Item 13.d:
d. Licensee agrees to comply with all applicable export and import laws and regulations, including
those of that apply to goods of United States origin and that prohibit or limit export for certain
uses or to certain users.
The following replaces Item 13.i:
i. No right or cause of action for any third party is created by this Agreement or any transaction
under it, nor is IBM responsible for any third party claims against Licensee except as permitted by
the Limitation of Liability section above for bodily injury (including death) or physical harm to
real or tangible personal property caused by IBM's negligence for which IBM is legally liable to
that third party.
The following is added as Item 13.m:
m. For purposes of this Item 13.m, "Personal Data" refers to information relating to an identified
or identifiable individual made available by one of the parties, its personnel or any other
individual to the other in connection with this Agreement. The following provisions apply in the
event that one party makes Personal Data available to the other:
(1) General
(a) Each party is responsible for complying with any obligations applying to it under applicable
Canadian data privacy laws and regulations ("Laws").
(b) Neither party will request Personal Data beyond what is necessary to fulfill the purpose(s) for
which it is requested. The purpose(s) for requesting Personal Data must be reasonable. Each party
will agree in advance as to the type of Personal Data that is required to be made available.
(2) Security Safeguards
(a) Each party acknowledges that it is solely responsible for determining and communicating to the
other the appropriate technological, physical and organizational security measures required to
protect Personal Data.
(b) Each party will ensure that Personal Data is protected in accordance with the security
safeguards communicated and agreed to by the other.
(c) Each party will ensure that any third party to whom Personal Data is transferred is bound by
the applicable terms of this section.
(d) Additional or different services required to comply with the Laws will be deemed a request for
new services.
(3) Use
Each party agrees that Personal Data will only be used, accessed, managed, transferred, disclosed
to third parties or otherwise processed to fulfill the purpose(s) for which it was made available.
(4) Access Requests
(a) Each party agrees to reasonably cooperate with the other in connection with requests to access
or amend Personal Data.
(b) Each party agrees to reimburse the other for any reasonable charges incurred in providing each
other assistance.
(c) Each party agrees to amend Personal Data only upon receiving instructions to do so from the
other party or its personnel.
(5) Retention
Each party will promptly return to the other or destroy all Personal Data that is no longer
necessary to fulfill the purpose(s) for which it was made available, unless otherwise instructed by
the other or its personnel or required by law.
(6) Public Bodies Who Are Subject to Public Sector Privacy Legislation
For Customers who are public bodies subject to public sector privacy legislation, this Item 13.m
applies only to Personal Data made available to Customer in connection with this Agreement, and the
obligations in this section apply only to Customer, except that: 1) section (2)(a) applies only to
IBM; 2) sections (1)(a) and (4)(a) apply to both parties; and 3) section (4)(b) and the last
sentence in (1)(b) do not apply.
PERU
10. Limitation of Liability
The following is added to the end of this Section 10 (Limitation of Liability):
Except as expressly required by law without the possibility of contractual waiver, Licensee and IBM
intend that the limitation of liability in this Limitation of Liability section applies to damages
caused by all types of claims and causes of action. If any limitation on or exclusion from
liability in this section is held by a court of competent jurisdiction to be unenforceable with
respect to a particular claim or cause of action, the parties intend that it nonetheless apply to
the maximum extent permitted by applicable law to all other claims and causes of action.
10.1 Items for Which IBM May be Liable
The following is added at the end of this Subsection 10.1:
In accordance with Article 1328 of the Peruvian Civil Code, the limitations and exclusions
specified in this section will not apply to damages caused by IBM's willful misconduct ("dolo") or
gross negligence ("culpa inexcusable").
UNITED STATES OF AMERICA:
5. Taxes
The following is added at the end of this Section 5 (Taxes)
For Programs delivered electronically in the United States for which Licensee claims a state sales
and use tax exemption, Licensee agrees not to receive any tangible personal property (e.g., media
and publications) associated with the electronic program.
Licensee agrees to be responsible for any sales and use tax liabilities that may arise as a result
of Licensee's subsequent redistribution of Programs after delivery by IBM.
13. General
The following is added to Section 13 as Item 13.m:
U.S. Government Users Restricted Rights - Use, duplication or disclosure is restricted by the GSA
IT Schedule 70 Contract with the IBM Corporation.
The following is added to Item 13.f:
Each party waives any right to a jury trial in any proceeding arising out of or related to this
Agreement.
ASIA PACIFIC COUNTRY AMENDMENTS
AUSTRALIA:
5. Taxes
The following sentences replace the first two sentences of Section 5 (Taxes):
If any government or authority imposes a duty, tax (other than income tax), levy, or fee, on this
Agreement or on the Program itself, that is not otherwise provided for in the amount payable,
Licensee agrees to pay it when IBM invoices Licensee. If the rate of GST changes, IBM may adjust
the charge or other amount payable to take into account that change from the date the change
becomes effective.
8.1 Limited Warranty
The following is added Subsection 8.1 (Limited Warranty):
The warranties specified this Section are in addition to any rights Licensee may have under the
Trade Practices Act 1974 or other legislation and are only limited to the extent permitted by the
applicable legislation.
10.1 Items for Which IBM May be Liable
The following is added to Subsection 10.1 (Items for Which IBM Maybe Liable):
Where IBM is in breach of a condition or warranty implied by the Trade Practices Act 1974, IBM's
liability is limited to the repair or replacement of the goods, or the supply of equivalent goods.
Where that condition or warranty relates to right to sell, quiet possession or clear title, or the
goods are of a kind ordinarily obtained for personal, domestic or household use or consumption,
then none of the limitations in this paragraph apply.
HONG KONG SAR, MACAU SAR, AND TAIWAN
As applies to licenses obtained in Taiwan and the special administrative regions, phrases
throughout this Agreement containing the word "country" (for example, "the country in which the
original Licensee was granted the license" and "the country in which Licensee obtained the Program
license") are replaced with the following:
(1) In Hong Kong SAR: "Hong Kong SAR"
(2) In Macau SAR: "Macau SAR" except in the Governing Law clause (Section 14.1)
(3) In Taiwan: "Taiwan."
INDIA
10.1 Items for Which IBM May be Liable
The following replaces the terms of Items 1 and 2 of the first paragraph:
1) liability for bodily injury (including death) or damage to real property and tangible personal
property will be limited to that caused by IBM's negligence; and 2) as to any other actual damage
arising in any situation involving nonperformance by IBM pursuant to, or in any way related to the
subject of this Agreement, IBM's liability will be limited to the charge paid by Licensee for the
individual Program that is the subject of the claim.
13. General
The following replaces the terms of Item 13.g:
If no suit or other legal action is brought, within three years after the cause of action arose, in
respect of any claim that either party may have against the other, the rights of the concerned
party in respect of such claim will be forfeited and the other party will stand released from its
obligations in respect of such claim.
INDONESIA
3.3 Term and Termination
The following is added to the last paragraph:
Both parties waive the provision of article 1266 of the Indonesian Civil Code, to the extent the
article provision requires such court decree for the termination of an agreement creating mutual
obligations.
JAPAN
13. General
The following is inserted after Item 13.f:
Any doubts concerning this Agreement will be initially resolved between us in good faith and in
accordance with the principle of mutual trust.
MALAYSIA
10.2 Items for Which IBM Is not Liable
The word "SPECIAL" in Item 10.2b is deleted.
NEW ZEALAND
8.1 Limited Warranty
The following is added:
The warranties specified in this Section are in addition to any rights Licensee may have under the
Consumer Guarantees Act 1993 or other legislation which cannot be excluded or limited. The Consumer
Guarantees Act 1993 will not apply in respect of any goods which IBM provides, if Licensee requires
the goods for the purposes of a business as defined in that Act.
10. Limitation of Liability
The following is added:
Where Programs are not obtained for the purposes of a business as defined in the Consumer
Guarantees Act 1993, the limitations in this Section are subject to the limitations in that Act.
PEOPLE'S REPUBLIC OF CHINA
4. Charges
The following is added:
All banking charges incurred in the People's Republic of China will be borne by Licensee and those
incurred outside the People's Republic of China will be borne by IBM.
PHILIPPINES
10.2 Items for Which IBM Is not Liable
The following replaces the terms of Item 10.2b:
b. special (including nominal and exemplary damages), moral, incidental, or indirect damages or for
any economic consequential damages; or
SINGAPORE
10.2 Items for Which IBM Is not Liable
The words "SPECIAL" and "ECONOMIC" are deleted from Item 10.2b.
13. General
The following replaces the terms of Item 13.i:
Subject to the rights provided to IBM's suppliers and Program developers as provided in Section 10
above (Limitation of Liability), a person who is not a party to this Agreement will have no right
under the Contracts (Right of Third Parties) Act to enforce any of its terms.
TAIWAN
8.1 Limited Warranty
The last paragraph is deleted.
10.1 Items for Which IBM May Be Liable
The following sentences are deleted
This limit also applies to any of IBM's subcontractors and Program developers. It is the maximum
for which IBM and its subcontractors and Program developers are collectively responsible.
EUROPE, MIDDLE EAST, AFRICA (EMEA) COUNTRY AMENDMENTS
EUROPEAN UNION MEMBER STATES
8. Warranty and Exclusions
The following is added to Section 8 (Warranty and Exclusion):
In the European Union ("EU"), consumers have legal rights under applicable national legislation
governing the sale of consumer goods. Such rights are not affected by the provisions set out in
this Section 8 Warranty and Exclusions. The territorial scope of the Limited Warranty is worldwide.
EU MEMBER STATES AND THE COUNTRIES IDENTIFIED BELOW
Iceland, Liechtenstein, Norway, Switzerland, Turkey, and any other European country that has
enacted local data privacy or protection legislation similar to the EU model.
13. General
The following replaces Item 13.e:
(1) Definitions - For the purposes of this Item 13.e, the following additional definitions apply:
(a) Business Contact Information - business-related contact information disclosed by Licensee to
IBM, including names, job titles, business addresses, telephone numbers and email addresses of
Licensee's employees and contractors. For Austria, Italy and Switzerland, Business Contact
Information also includes information about Customer and its contractors as legal entities (for
example, Customer's revenue data and other transactional information)
(b) Business Contact Personnel - Licensee employees and contractors to whom the Business Contact
Information relates.
(c) Data Protection Authority - the authority established by the Data Protection and Electronic
Communications Legislation in the applicable country or, for non-EU countries, the authority
responsible for supervising the protection of personal data in that country, or (for any of the
foregoing) any duly appointed successor entity thereto.
(d) Data Protection & Electronic Communications Legislation - (i) the applicable local legislation
and regulations in force implementing the requirements of EU Directive 95/46/EC (on the protection
of individuals with regard to the processing of personal data and on the free movement of such
data) and of EU Directive 2002/58/EC (concerning the processing of personal data and the protection
of privacy in the electronic communications sector); or (ii) for non-EU countries, the legislation
and/or regulations passed in the applicable country relating to the protection of personal data and
the regulation of electronic communications involving personal data, including (for any of the
foregoing) any statutory replacement or modification thereof.
(e) IBM Group - International Business Machines Corporation of Armonk, New York, USA, its
subsidiaries, and their respective Business Partners and subcontractors.
(2) Licensee authorises IBM:
(a) to process and use Business Contact Information within IBM Group in support of Licensee
including the provision of support services, and for the purpose of furthering the business
relationship between Licensee and IBM Group, including, without limitation, contacting Business
Contact Personnel (by email or otherwise) and marketing IBM Group products and services (the
"Specified Purpose"); and
(b) to disclose Business Contact Information to other members of IBM Group in pursuit of the
Specified Purpose only.
(3) IBM agrees that all Business Contact Information will be processed in accordance with the Data
Protection & Electronic Communications Legislation and will be used only for the Specified Purpose.
(4) To the extent required by the Data Protection & Electronic Communications Legislation, Licensee
represents that (a) it has obtained (or will obtain) any consents from (and has issued (or will
issue) any notices to) the Business Contact Personnel as are necessary in order to enable IBM Group
to process and use the Business Contact Information for the Specified Purpose.
(5) Licensee authorises IBM to transfer Business Contact Information outside the European Economic
Area, provided that the transfer is made on contractual terms approved by the Data Protection
Authority or the transfer is otherwise permitted under the Data Protection & Electronic
Communications Legislation.
AUSTRIA
8.2 Exclusions
The following is deleted from the first paragraph:
MERCHANTABILITY, SATISFACTORY QUALITY
10. Limitation of Liability
The following is added:
The following limitations and exclusions of IBM's liability do not apply for damages caused by
gross negligence or willful misconduct.
10.1 Items for Which IBM May Be Liable
The following replaces the first sentence in the first paragraph:
Circumstances may arise where, because of a default by IBM in the performance of its obligations
under this Agreement or other liability, Licensee is entitled to recover damages from IBM.
In the second sentence of the first paragraph, delete entirely the parenthetical phrase:
"(including fundamental breach, negligence, misrepresentation, or other contract or tort claim)".
10.2 Items for Which IBM Is Not Liable
The following replaces Item 10.2b:
b. indirect damages or consequential damages; or
BELGIUM, FRANCE, ITALY, AND LUXEMBOURG
10. Limitation of Liability
The following replaces the terms of Section 10 (Limitation of Liability) in its entirety:
Except as otherwise provided by mandatory law:
10.1 Items for Which IBM May Be Liable
IBM's entire liability for all claims in the aggregate for any damages and losses that may arise as
a consequence of the fulfillment of its obligations under or in connection with this Agreement or
due to any other cause related to this Agreement is limited to the compensation of only those
damages and losses proved and actually arising as an immediate and direct consequence of the
non-fulfillment of such obligations (if IBM is at fault) or of such cause, for a maximum amount
equal to the charges (if the Program is subject to fixed term charges, up to twelve months'
charges) Licensee paid for the Program that has caused the damages.
The above limitation will not apply to damages for bodily injuries (including death) and damages to
real property and tangible personal property for which IBM is legally liable.
10.2 Items for Which IBM Is Not Liable
UNDER NO CIRCUMSTANCES IS IBM OR ANY OF ITS PROGRAM DEVELOPERS LIABLE FOR ANY OF THE FOLLOWING,
EVEN IF INFORMED OF THEIR POSSIBILITY: 1) LOSS OF, OR DAMAGE TO, DATA; 2) INCIDENTAL, EXEMPLARY OR
INDIRECT DAMAGES, OR FOR ANY ECONOMIC CONSEQUENTIAL DAMAGES; AND / OR 3) LOST PROFITS, BUSINESS,
REVENUE, GOODWILL, OR ANTICIPATED SAVINGS, EVEN IF THEY ARISE AS AN IMMEDIATE CONSEQUENCE OF THE
EVENT THAT GENERATED THE DAMAGES.
10.3 Suppliers and Program Developers
The limitation and exclusion of liability herein agreed applies not only to the activities
performed by IBM but also to the activities performed by its suppliers and Program developers, and
represents the maximum amount for which IBM as well as its suppliers and Program developers are
collectively responsible.
GERMANY
8.1 Limited Warranty
The following is inserted at the beginning of Section 8.1:
The Warranty Period is twelve months from the date of delivery of the Program to the original
Licensee.
8.2 Exclusions
Section 8.2 is deleted in its entirety and replaced with the following:
Section 8.1 defines IBM's entire warranty obligations to Licensee except as otherwise required by
applicable statutory law.
10. Limitation of Liability
The following replaces the Limitation of Liability section in its entirety:
a. IBM will be liable without limit for 1) loss or damage caused by a breach of an express
guarantee; 2) damages or losses resulting in bodily injury (including death); and 3) damages caused
intentionally or by gross negligence.
b. In the event of loss, damage and frustrated expenditures caused by slight negligence or in
breach of essential contractual obligations, IBM will be liable, regardless of the basis on which
Licensee is entitled to claim damages from IBM (including fundamental breach, negligence,
misrepresentation, or other contract or tort claim), per claim only up to the greater of 500,000
euro or the charges (if the Program is subject to fixed term charges, up to 12 months' charges)
Licensee paid for the Program that caused the loss or damage. A number of defaults which together
result in, or contribute to, substantially the same loss or damage will be treated as one default.
c. In the event of loss, damage and frustrated expenditures caused by slight negligence, IBM will
not be liable for indirect or consequential damages, even if IBM was informed about the possibility
of such loss or damage.
d. In case of delay on IBM's part: 1) IBM will pay to Licensee an amount not exceeding the loss or
damage caused by IBM's delay and 2) IBM will be liable only in respect of the resulting damages
that Licensee suffers, subject to the provisions of Items a and b above.
13. General
The following replaces the provisions of 13.g:
Any claims resulting from this Agreement are subject to a limitation period of three years, except
as stated in Section 8.1 (Limited Warranty) of this Agreement.
The following replaces the provisions of 13.i:
No right or cause of action for any third party is created by this Agreement, nor is IBM
responsible for any third party claims against Licensee, except (to the extent permitted in Section
10 (Limitation of Liability)) for: i) bodily injury (including death); or ii) damage to real or
tangible personal property for which (in either case) IBM is legally liable to that third party.
IRELAND
8.2 Exclusions
The following paragraph is added:
Except as expressly provided in these terms and conditions, or Section 12 of the Sale of Goods Act
1893 as amended by the Sale of Goods and Supply of Services Act, 1980 (the "1980 Act"), all
conditions or warranties (express or implied, statutory or otherwise) are hereby excluded
including, without limitation, any warranties implied by the Sale of Goods Act 1893 as amended by
the 1980 Act (including, for the avoidance of doubt, Section 39 of the 1980 Act).
IRELAND AND UNITED KINGDOM
2. Agreement Structure
The following sentence is added:
Nothing in this paragraph shall have the effect of excluding or limiting liability for fraud.
10.1 Items for Which IBM May Be Liable
The following replaces the first paragraph of the Subsection:
For the purposes of this section, a "Default" means any act, statement, omission or negligence on
the part of IBM in connection with, or in relation to, the subject matter of an Agreement in
respect of which IBM is legally liable to Licensee, whether in contract or in tort. A number of
Defaults which together result in, or contribute to, substantially the same loss or damage will be
treated as one Default.
Circumstances may arise where, because of a Default by IBM in the performance of its obligations
under this Agreement or other liability, Licensee is entitled to recover damages from IBM.
Regardless of the basis on which Licensee is entitled to claim damages from IBM and except as
expressly required by law without the possibility of contractual waiver, IBM's entire liability for
any one Default will not exceed the amount of any direct damages, to the extent actually suffered
by Licensee as an immediate and direct consequence of the default, up to the greater of (1) 500,000
euro (or the equivalent in local currency) or (2) 125% of the charges (if the Program is subject to
fixed term charges, up to 12 months' charges) for the Program that is the subject of the claim.
Notwithstanding the foregoing, the amount of any damages for bodily injury (including death) and
damage to real property and tangible personal property for which IBM is legally liable is not
subject to such limitation.
10.2 Items for Which IBM is Not Liable
The following replaces Items 10.2b and 10.2c:
b. special, incidental, exemplary, or indirect damages or consequential damages; or
c. wasted management time or lost profits, business, revenue, goodwill, or anticipated savings.
Z125-3301-13 (05/2009)
LICENSE INFORMATION
The Programs listed below are licensed under the following terms and conditions in addition to
those of the International Program License Agreement.
Program Name: IBM Tivoli Storage Manager V6.3
Program Number: 5608-E01
Supporting Programs
The Program is licensed as a multi-product package and includes the Supporting Programs identified
below. Licensee is authorized to install and use such Supporting Programs only to support
Licensee's use of the Principal Program under this Agreement and within the limits of the Proofs of
Entitlement for the Program (unless broader rights are provided elsewhere in this License
Information document). The phrase "to support Licensee's use" would include only those uses that
are necessary or otherwise directly related to a licensed use of the Principal Program or another
Supporting Program. The Supporting Programs may not be used for any other purpose. Licensee is not
authorized to transfer or remarket the Supporting Programs separate from the Principal Program. The
terms of this Agreement may replace or modify the license terms for the Supporting Programs. In the
event of conflict, these terms supersede the terms of the license agreement which accompanies the
Supporting Programs. When Licensee's right to use the Program expires or terminates, Licensee must
discontinue use, destroy or promptly return all copies of the Supporting Programs to the party from
whom Licensee acquired the Program. If Licensee downloaded the Supporting Programs, Licensee should
contact the party from whom Licensee acquired the Program. If Licensee wishes to license the
Supporting Programs for any use beyond the limits set forth above, please contact an IBM Sales
Representative or the party from whom Licensee acquired the Program to obtain the appropriate
license.
The following are Supporting Programs licensed with the Program:
IBM DB2 Enterprise Server Edition V9.7 for Linux, UNIX, and Windows
eWAS - embedded version of IBM WebSphere Application Server ("embedded WebSphere Application
Server"). [version 7.0.0.x]
IBM Tivoli Common Reporting v2.1
IBM Tivoli Monitoring, Version 6
Prohibited Components
Notwithstanding any provision in the Agreement, Licensee is not authorized to use any of the
following components or functions of the Program:
SET ARCHIVERETENTIONPROTECTION command
Disaster Recovery Manager
Network Data Management Protocol (NDMP) Backup
Node replication (and use of the REPLICATE NODE command as a target server)
Geodetic Data Management Feature (of IBM DB2)
Homogeneous Replication Feature (of IBM DB2)
Advanced Access Control Feature (of IBM DB2)
Performance Optimization Feature (of IBM DB2)
Separately Licensed Code
The provisions of this paragraph do not apply to the extent they are held to be invalid or
unenforceable under the law that governs this license. Each of the components listed below is
considered "Separately Licensed Code". IBM Separately Licensed Code is licensed to Licensee under
the terms of the applicable third party license agreement(s) set forth in the NON_IBM_LICENSE
file(s) that accompanies the Program. Notwithstanding any of the terms in the Agreement, or any
other agreement Licensee may have with IBM, the terms of such third party license agreement(s)
governs Licensee's use of all Separately Licensed Code unless otherwise noted below.
Future Program updates or fixes may contain additional Separately Licensed Code. Such additional
Separately Licensed Code and related licenses are listed in another NON_IBM_LICENSE file that
accompanies the Program update or fix. Licensee acknowledges that Licensee has read and agrees to
the license agreements contained in the NON_IBM_LICENSE file(s). If Licensee does not agree to the
terms of these third party license agreements, Licensee may not use the Separately Licensed Code.
For Programs acquired under the International Program License Agreement ("IPLA") or International
Program License Agreement for Non Warranted Program ("ILAN") and Licensee is the original licensee
of the Program, if Licensee does not agree with the third party license agreements, Licensee may
return the Program in accordance with the terms of, and within the specified time frames stated in,
the "Money-back Guarantee" section of the IPLA or ILAN IBM Agreement.
Note: Notwithstanding any of the terms in the third party license agreement, the Agreement, or any
other agreement Licensee may have with IBM:
(a) IBM provides this Separately Licensed Code to Licensee WITHOUT WARRANTIES OF ANY KIND;
(b) IBM DISCLAIMS ANY AND ALL EXPRESS AND IMPLIED WARRANTIES AND CONDITIONS INCLUDING, BUT NOT
LIMITED TO, THE WARRANTY OF TITLE, NON-INFRINGEMENT OR INTERFERENCE AND THE IMPLIED WARRANTIES AND
CONDITIONS OF MERCHANTABILITY AND FITNESS FOR A PARTICULAR PURPOSE, WITH RESPECT TO THE SEPARATELY
LICENSED CODE;
(c) IBM is not liable to Licensee, and will not defend, indemnify, or hold Licensee harmless for
any claims arising from or related to the Separately Licensed Code; and
(d) IBM is not liable for any direct, indirect, incidental, special, exemplary, punitive or
consequential damages including, but not limited to, lost data, lost savings, and lost profits,
with respect to the Separately Licensed Code.
Notwithstanding these exclusions, in Germany and Austria, IBM's warranty and liability for the
Separately Licensed Code is governed only by the respective terms applicable for Germany and
Austria in IBM license agreements.
Note: IBM may provide limited support for some Separately Licensed Code. If such support is
available, the details and any additional terms related to such support will be set forth in the
License Information document.
The following are Separately Licensed Code:
Linux Filepath 1.0.0
Source Components and Sample Materials
The Program may include some components in source code form ("Source Components") and other
materials identified as Sample Materials. Licensee may copy and modify Source Components and Sample
Materials for internal use only provided such use is within the limits of the license rights under
this Agreement, provided however that Licensee may not alter or delete any copyright information or
notices contained in the Source Components or Sample Materials. IBM provides the Source Components
and Sample Materials without obligation of support and "AS IS", WITH NO WARRANTY OF ANY KIND,
EITHER EXPRESS OR IMPLIED, INCLUDING THE WARRANTY OF TITLE, NON-INFRINGEMENT OR NON-INTERFERENCE
AND THE IMPLIED WARRANTIES AND CONDITIONS OF MERCHANTABILITY AND FITNESS FOR A PARTICULAR PURPOSE.
Export and Import Restrictions
This Program may contain cryptography. Transfer to, or use by, users of the Program may be
prohibited or subject to export or import laws, regulations or policies, including those of the
United States Export Administration Regulations. Licensee assumes all responsibility for complying
with all applicable laws, regulations, and policies regarding the export, import, or use of this
Program, including but not limited to, U.S. restrictions on exports or reexports. To obtain the
export classification of this Program refer to: https://www.ibm.com/products/exporting/.
Client Device
Client Device is a unit of measure by which the Program can be licensed. A Client Device is a
single user computing device or special purpose sensor or telemetry device that requests the
execution of or receives for execution a set of commands, procedures, or applications from or
provides data to another computer system that is typically referred to as a server or is otherwise
managed by the server. Multiple Client Devices may share access to a common server. A Client Device
may have some processing capability or be programmable to allow a user to do work. Examples
include, but are not limited to actuators, appliances, automated teller machines, automatic meter
readers, cash registers, disk drives, desktop computers, kiosks, notebook computers, personal
digital assistant, point-of-sale terminals, sensors, smart meters, tape drives, and technical
workstations. Licensee must obtain entitlements for every Client Device which runs, provides data
to, uses services provided by, or otherwise accesses the Program and for every other computer or
server on which the Program is installed.
Processor Value Unit (PVU)
Processor Value Unit (PVU) is a unit of measure by which the Program can be licensed. The number of
PVU entitlements required is based on the processor technology (defined within the PVU Table by
Processor Vendor, Brand, Type and Model Number at
http://www.ibm.com/software/lotus/passportadvantage/pvu_licensing_for_customers.html) and the
number of processors made available to the Program. IBM continues to define a processor, for the
purpose of PVU-based licensing, to be each processor core on a chip. A dual-core processor chip,
for example, has two processor cores.
Licensee can deploy the Program using either Full Capacity licensing or Virtualization Capacity
(Sub-Capacity) licensing according to the Passport Advantage Sub-Capacity Licensing Terms (see
webpage below). If using Full Capacity licensing, Licensee must obtain PVU entitlements sufficient
to cover all activated processor cores* in the physical hardware environment made available to or
managed by the Program, except for those servers from which the Program has been permanently
removed. If using Virtualization Capacity licensing, Licensee must obtain entitlements sufficient
to cover all activated processor cores made available to or managed by the Program, as defined
according to the Virtualization Capacity License Counting Rules at
http://www.ibm.com/software/lotus/passportadvantage/Counting_Software_licenses_using_specific_virtua
lization_technologies.html.
* An Activated processor core is a processor core that is available for use in a physical or
virtual server, regardless of whether the capacity of the processor core can be or is limited
through virtualization technologies, operating system commands, BIOS settings, or similar
restrictions.
In addition to the entitlements required for the Program directly, Licensee must obtain PVU
entitlements for this Program sufficient to cover the processor cores for the systems on which the
resources managed or processed by the Program reside.
Program-unique Terms
Licensee is not permitted to use the Program to support tape libraries (including Virtual Tape
Libraries) with more than four drives or more than 48 slots.
Supporting Program Details - IBM DB2
The following applies to use of the IBM DB2 edition(s) specified in the Supporting Programs section
of this License Information:
- Entitlement: Ratio 1/1
- Use Limitations: Use by Principal Program
"Ratio n/m" means that Licensee receives some number ('n') entitlements for the Supporting Program
for every specified number ('m') entitlements of the Principal Program as a whole. Unless otherwise
specified, the number of entitlements for the Supporting Program is rounded up to a multiple of
'n'. For example, if a Program includes 100 PVUs for a Supporting Program for every 500 PVUs
obtained of the Principal Program and Licensee acquires 1,200 PVUs of the Program, Licensee may
install the Supporting Program and have processor cores available to or managed by it of up to 300
PVUs. Those PVUs would not need to be counted as part of the total PVU requirement for Licensee's
installation of the Program on account of the installation of the Supporting Program (although
those PVUs might need to be counted for other reasons, such as the processor cores being made
available to the Principal Program, as well).
"Use by Principal Program" means that the Supporting Program is provided exclusively for use by the
Principal Program. Neither Licensee nor any application, program or device is authorized to
directly use or access the services of the Supporting Program except Licensee may access the
Supporting Program to perform administrative functions for the Supporting Program such as backup,
recovery and authorized configuration
The Program is accompanied by an embedded version of IBM WebSphere Application Server ("embedded
WAS").
Disabling Device
The embedded Program may include a disabling device that will prevent certain features from being
used. Licensee will not tamper with such disabling device or otherwise change the embedded Program.
Unlimited Copy Components
Licensee is authorized to install and use an unlimited number of copies of the Administrative
Scripting Program component on any Licensee machines to support your authorized use of the other
components of the embedded Program.
Source Code
Some of the components of the Program may be provided in source code form. Notwithstanding anything
to the contrary in this Agreement, support is only provided for the unmodified, binary code
versions of these components included in the Program packaging, and not for the source code for
these components or for any modifications of such components Licensee may create.
D/N: L-BEBY-8DWSC7
P/N: L-BEBY-8DWSC7
